Serving Paso Robles, CA and surrounding areas. (805) 257-0239
Effective Date: January 1, 2026
By visiting concretepasorobles.com, submitting a contact form, calling our office, or entering into a service agreement with Paso Robles Concrete Contractors ("we," "us," or "our"), you agree to be bound by these Terms and Conditions. If you do not agree to these terms, please do not use our website or engage our services.
These terms apply to all visitors, prospective customers, and current customers of Paso Robles Concrete Contractors. We may update these terms at any time by posting a revised version on our website. Continued use of our site or services after a change constitutes acceptance of the updated terms.
Paso Robles Concrete Contractors provides residential and commercial concrete contracting services in Paso Robles, CA and surrounding communities. Services include but are not limited to: concrete driveway building, patio construction, stamped concrete, sidewalk building, garage floor concrete, decorative concrete, retaining walls, concrete floor installation, pool decks, steps construction, slab foundation building, foundation installation, parking lot building, footings, foundation raising, and concrete cutting.
All services are subject to site assessment and contractor availability. We reserve the right to decline any project at our discretion, including projects outside our service area or scope of work.
On-site project estimates are provided at no charge and with no obligation to hire us. Estimates are based on the site conditions observed at the time of the visit and the project scope described by the customer. All estimates are provided in writing and include a breakdown of materials, labor, and any applicable permit fees.
A written estimate is valid for 30 days from the date of issue unless otherwise noted. After 30 days, material costs and labor rates may change. We will notify you of any changes before proceeding.
If unforeseen conditions are discovered during the course of work, such as unstable soils, buried obstructions, or conditions not visible during the estimate visit, we will stop work and notify you before proceeding with any scope or cost change. No additional work will begin without your written approval of a change order.
Project start dates are scheduled after a signed contract and any required deposit are received. Scheduling is subject to weather conditions, permit timelines, and contractor availability. We will communicate expected start dates clearly and notify you as early as possible of any changes.
Cancellations by the customer before work begins may result in forfeiture of any deposit paid, as outlined in the individual service agreement. Cancellations after work has begun may result in charges for work completed, materials ordered or delivered, and any permit fees already incurred.
We reserve the right to reschedule or postpone work due to weather, permitting delays, or other conditions outside our control. We will provide notice as promptly as possible in such cases.
Payment terms are specified in the individual service agreement for each project. A deposit is typically required before work begins. The remaining balance is due upon project completion unless otherwise agreed to in writing.
We accept payment by cash, check, or other methods as specified in the service agreement. Returned checks are subject to a returned check fee. Late payments may accrue interest at the maximum rate permitted by California law.
Work may be paused if payment milestones are not met as scheduled. We reserve the right to place a mechanics lien on your property in accordance with California law if payment is not received as agreed.
Where required by local law, we will obtain applicable building permits on behalf of the customer before work begins. Permit fees are typically passed through at cost and are itemized in the written estimate. The customer is responsible for ensuring access to the property during any required city or county inspections.
All work is performed in compliance with applicable building codes and regulations for Paso Robles, CA and surrounding jurisdictions. We do not perform work without required permits and do not recommend customers skip the permit process.
The customer is responsible for providing accurate information about the property, including existing underground utilities, easements, and property boundaries. Before any excavation begins, we require that utility lines be marked by the appropriate authority. The customer should call 811 (Dig Safe) or the appropriate California utility notification service before any digging begins if not already arranged by the contractor.
The customer is responsible for ensuring clear access to the work area on scheduled days, including removal of vehicles, furniture, or other obstructions. Delays caused by lack of access may result in rescheduling fees.
Specific warranty terms for completed work are provided in the individual service agreement. In general, we stand behind our workmanship for the period specified in writing for each project.
Concrete is a natural material and minor surface cracking, color variation, and surface weathering are normal characteristics, not defects. Warranty claims do not apply to damage caused by improper use, unusual weather events, soil conditions not disclosed prior to the estimate, or customer modifications to completed work.
Except as expressly stated in the written service agreement, all services are provided "as is" without any additional warranties, express or implied. We disclaim all implied warranties to the maximum extent permitted by California law.
To the maximum extent permitted by applicable law, Paso Robles Concrete Contractors shall not be liable for any indirect, incidental, consequential, or punitive damages arising out of or related to our services or your use of our website, even if we have been advised of the possibility of such damages.
Our total liability for any claim arising from a completed project shall not exceed the total amount paid by the customer for that project. This limitation applies regardless of the form of action, whether in contract, tort, or otherwise.
The content on concretepasorobles.com is provided for general informational purposes. We make no representations or warranties about the accuracy, completeness, or suitability of the content for any particular purpose. Content may be updated without notice.
You may not use our website for any unlawful purpose, to submit false or misleading information, to attempt to gain unauthorized access to our systems, or to interfere with the operation of the site in any way.
If a dispute arises between you and Paso Robles Concrete Contractors related to our services or these terms, we encourage you to contact us first so we can try to resolve the matter directly. Please reach out to us at contact@concretepasorobles.com or (805) 257-0239.
If we cannot resolve the dispute informally, both parties agree to attempt mediation in Paso Robles, CA before pursuing formal legal action. Nothing in this section limits your right to file a complaint with the California Contractors State License Board (CSLB) or other applicable regulatory authority.
These Terms and Conditions and any disputes arising from them are governed by and construed in accordance with the laws of the State of California, without regard to conflict of law principles. Any legal action must be brought in a court of competent jurisdiction in San Luis Obispo County, California.
We reserve the right to update these Terms and Conditions at any time. Changes will be posted on this page with an updated effective date. It is your responsibility to review these terms periodically. Your continued use of our website or services after a change is posted constitutes your acceptance of the updated terms.
If you have questions about these Terms and Conditions, please contact us:
Paso Robles Concrete Contractors
1408 Crown Way
Paso Robles, CA 93446
contact@concretepasorobles.com(805) 257-0239Return to Home, learn more on our About page, or Contact us with any questions.
